991664

ReadAboutContentsHelp
Kerns Brothers, contractors for the street improvement on Dexter Street, requested sixty day time extension in which to complete the project. They claimed that they had been delayed by poor weather. The Committee on Streets recommended that the petition be granted. See full description in Digital Collections

Pages

991664_Page_1
Indexed

991664_Page_1

31 3//1/91 to [?] & Council Kerns Bros 2 Dexter St Petition for extension of time Your Com. on Streets recommend that the petition be granted and the time for completion of Dexter St be extended to March 1st 1890 T E Jones chairman F A Twitchell com

Last edit almost 3 years ago by StephanieJoWebb
991664_Page_2
Indexed

991664_Page_2

To the hon Mayor & Common Council of the City of Seattle King County Washington We the undersigned petitioners respectfully represent that they are the contractors who entered into an agreement with your Hon body to grade and sidewalk Dexter Street in said City between Depot Street and James Street at the boundry line of Union Lake Additions to said city. that owing to the inclemency of the weather for upwards os six weeks lost past and his and want of a definate grade being established on said street until about the 15th day of November last your petitioners have been unable to finish said grade and sidewalks within the time called for by their said contract and your petitioners pray for an extension of 60 days from this date to complete the contract on their part. Dated January 2nd 1890 Kerns Bros

Last edit almost 3 years ago by StephanieJoWebb
Displaying all 2 pages